Image provided by: University of Oregon Libraries; Eugene, OR
About The Blue Mountain eagle. (John Day, Or.) 1972-current | View Entire Issue (Sept. 30, 2020)
CLASSIFIEDS Blue Mountain Eagle 999 Statewide Classifieds SUBSCRIBE TODAY DONATE YOUR CAR TO UNIT- ED BREAST CANCER FOUN- DATION! Your donation helps education, prevention & support programs. FAST FREE PICKUP - 24 HR RESPONSE - TAX DE- DUCTION. 1-855-252-2579. $45 1 year in county $85 2 years in county $57 1 year out of county $107 2 years out of county MYEAGLENEWS.COM Wednesday, September 30, 2020 101 Legal Notices GAME ANSWERS 2020 LEGAL NOTICE OF UNCLAIMED CAPITAL CREDITS Oregon Trail Electric Cooperative (OTEC) hereby gives notice of UNCLAIMED PAYMENTS OF CAPITAL CREDITS OR OTHER CREDITS OWED TO THE NAMED PERSONS ON RECORD. Such unclaimed capital credits or other credits have been avail- able to OTEC Members since December 31, 2016. Pursuant to OTEC bylaws and policy, the names of OTEC Mem- bers entitled to capital credit refunds – who have not yet claimed their refunds – can be reviewed on the OTEC website at: www.otec.coop/capital-credits If you are an OTEC Member and current (or former) consumer of OTEC, please check the OTEC website and list of Members who have failed to claim capital credits owed. Application for re-issuing funds owed may be made at your local OTEC office or 4005 23rd Street, PO Box 226, Baker City, Oregon 97814. Unless those persons named or their heirs claim payment no later than January 1, 2021, the unclaimed funds will be forfeit- ed to the Cooperative or, where required, forwarded to the De- partment of State Lands. Historically, the Board of Directors has contributed the amount of the forfeited funds to the Oregon Trail Electric Cooperative Scholarship Fund to benefit those served by the Cooperative. Legal Notices Publishing in Baker County, Oregon (Baker City Herald - August, September, October and November 2020), Union County, Oregon (La Grande Observer – August, September, October, November 2020), Harney County, Ore- gon (Burns Times-Herald – August, September, October and November 2020), Grant County, Oregon (Blue Mountain Eagle – August, September, October and November 2020) HOCUS-FOCUS DIFFERENCES: 1. BEAR HAS BEEN ADDED. 2. WINDOW IS WIDER. 3. PANTS ARE LONGER. 4. FLOWERS HAVE BEEN ADDED. 5. BUSHES HAVE BEEN ADDED. 6. TREE HAS ADDITIONAL LIMB. 541-575-0710 START YOUR DAY OUT RIGHT MYEAGLENEWS.COM 101 Legal Notices 101 Legal Notices CITY OF DAYVILLE – ADVERTISEMENT FOR BID RENOVATION & ALTERATION OF DAYVILLE COMMUNITY HALL LOCATED AT: 132 WEST FRANKLIN AVENUE DAYVILLE, OREGON 97825 Bids due 2:00 PM October 28th, 2020. INVITATION TO BID Your firm is invited to submit separate sealed bids under seal to City of Dayville for the construction of a building located at: 132 West Franklin Ave. Dayville, Oregon 97825 Before 2:00 PM local standard time on the 28th day of October, 2020, for the following project. Bids will be publicly opened and read aloud. Bids received after 2:00 PM on the above date will not be received or considered. Bids will be available for public inspection after opening. Project Description: Upgrade to existing 5,527 SF Community Center (1,014 SF of which will be demolished with a 916 SF addi- tion (with a kitchen, a meeting room, and upgrading bathrooms), external utility connections, parking lot improvements and land- scaping. Refer to other bidding requirements described in Documents 00 2113 Instructions to Bidders. All bidding contractors are required to attend a pre-bid building walk-through, at the existing facility, on October 14th, 2020 at 11:00 AM. Masks are to be worn at all times per state of Oregon requirements. Masks will be provided on site. Submit your offer on the Bid Form provided. Submit bids to the Owner, City of Dayville ATTN: Ruth Moore, at the City of Dayville Community Church Social Room, located at 200 South Fork Road, Dayville, Oregon. Masks are to be worn at all times per state of Oregon requirements. Masks will be provided on site. Provide all required bid documents in a sealed envelope as de- scribed in the instructions to bidders. Plainly mark the outside of the sealed envelope with the project name, bid date and time, bid- ders name and contractor’s Oregon State CCB license number. Within two hours of the bid closing, a separate sealed envelope containing the First-Tier Subcontractor Disclosure form is due. This advertisement for bid does not commit the Owner to award a contract nor to pay any costs incurred in the preparation of bids or the procurement of supplies. The Owner may reject a bid that does not comply with prescribed public contracting procedures and requirements, including the requirement to demonstrate the bidder’s responsibility under ORS 279.C.375 (3) (b). The Owner may also reject for good cause all bids after finding that doing so is in the public interest. License: Contractor shall be registered with the Oregon Con- struction Contractors Board and must be licensed under ORS 468A.720. A bid made to the contracting agency under ORS 279C.335 or 279C..400 must be in writing or filed with the person the contracting agency designates to receive bids. Work under this contract will be funded in part with federal grant funds from the Oregon Community Development Block Grant pro- gram. Prevailing Wages apply to this project according to current Oregon Bidding Requirements. The Higher wage rate from either BOLI or Davis Bacon will apply, subject to ORS 279C.800-279C.870 or Da- vis Bacon Act 40 U.S.C.3141. A bidder shall submit or post a surety bond irrevocable letter of credit issued by an insured institution as defined by ORS 706.008, Cashier’s check or certified check for all bids as bid security unless the contracting agency has exempted the contract for which the bidder submits a bid from this requirement under ORS 279C.390. The security shall be a minimum of 5% of the amount of the bid amount and may not exceed ten percent (10%) of the amount bid for the contract. Contractor is responsible for paying required building permit, li- censes, inspection fees, and taxes that may be required. Utility connection, impact fees and Fire Life and Safety Permit fee to be paid by the Owner. Utilities include: Power, Gas, Water, Sewer, Telephone. Contractor is responsible for securing and payment of building, mechanical, electrical, and plumbing permits and other govern- mental fees, licenses, and inspections necessary for proper ex- ecution of and completion of the Contract, see RD Instructions 1924-A Guide 1, Attachment 10. Unless exempt, the Contractor must file a Public Works Bond for $30,000 with the Construction Contractors Board before begin- ning work on the Project. Bid Questions: All bid questions pertaining to this project should be addressed to: Melanie Whedon at Pinnacle Architecture, Inc. Phone: 541-388-9897 Email: Melanie@parch.biz Plan Availability: To view or obtain copies of the bid documents, requests shall be made to: Skyliner Print and Design 1151 Cen- tennial Court, #3, Bend, OR 97702 Email: print@skylinerprint.com Phone: 541-749-2151 All contracts shall contain a provision requiring compliance with Executive Order 11246, entitled, “Equal Employment Opportunity,” as amended by Executive Order 11375 and as supplemented in Department of Labor regulations (41 CFR Part 60). If you have questions, please contact OTEC at 541-523-3616 S208912-1 FACEBOOK.COM/MYEAGLENEWS KEEP YOUR AD IN DEMAND WITH Searching for your next FULL COLOR Place an Eagle Help Wanted ad today and reach over 6,000 Readers each week. Plus, reach Call 541-575-0710 or go online at MyEagleNews.com 90,000 Visitors on MyEagleNews.com at no additional cost. 101 Legal Notices To place your ad today 101 Legal Notices RUSSELL YOUNG, Case No.: 20CV30273 Plaintiff, v. LAND IN BLOCK G, CITY OF JOHN DAY, Defendant. Land in Block G, City of John Day, situated in the NW1/4NE1/4 Section 26, T.13S, R.31E., W.M., Grant County, Oregon, described as follows: Beginning at 5/8” iron pin at the Northeast Corner of that certain tract of land described as TRACT I on Deed Records Instrument No. 20140340, said iron pin being N.17º29”18”E., 267.21 feet from the Southwest Corner of the NW1/4NE1/4 of said Section 26; thence along the west line of that certain tract of land described as TRACT II on said Deed Record Instrument No. 20140340, S.10º30’56”W., 209.5 feet, more or less, to the north line of that certain tract of land conveyed to the City of John Day in Deed Book 43, page 152; thence along said north line, West, 26.5 feet, more or less, to the east line of that tract of land described as TRACT I on Deed Record Instrument No. 20140340; thence along said east line, N.17º29’18”E, 215.3 feet, more or less to the point of beginning. Known herein as LAND IN BLOCK G, CITY OF JOHN DAY. Place your ad online or over the phone now! MyEagleNews.com 541-575-0710 All persons having claims against or interest in the subject property are required to present them by filing an answer or motion or reply with the court within 30 days of the date of first publication of this notice along with the required filing fee and serve the undersigned attorneys for the plaintiff at 206 S. Humbolt, Canyon City, OR 97820, within or the claims may be barred. The first date of publication occurred on September 30, 2020. All persons whose rights may be affected by the proceedings may obtain additional information from the records of the Court or the lawyers for Plaintiff, Russell Young. Attorneys for Plaintiff: Robert S. Raschio, OSB 013864 Strawberry Mountain Law, P.C. 206 South Humbolt Street, Canyon City, OR 97820 Telephone: (541) 575-5750 office@rrlaw.biz A Services Directory listing is $9.95 per week for a single ad (13 week minimum). Call the Blue Mountain Eagle today! 541-575-0710. JANITORIAL SERVICE 541-932-4411 ortelco.net NURSERY Better Blooms & Gardens Eastern Oregon Building Maintenance “Professional Cleaning Service” FIBER FAST INTERNET, PHONE & EZVideo ! 541-575-1741 • 1-800-282-1741 PORTA POTTY SANITATION CLARK’S ANDY’S PLUMBING & SPORTS TRANSFER STATION • Clean, sanitized • Portable • Septic tank pumping • We deliver & pick up 245 N. Canyon Blvd., Canyon City DISPOSAL 541-575-2144 ROLL OFF CONTAINERS FOR LARGE JOBS Serving John Day, Canyon City, Prairie City, CCB#181941 Mt. Vernon & Dayville Mon.-Fri. 8am-4:30pm Sports Store: Mon.-Thurs. 8am-4:30pm VETERINARY 541-575-0432 WELL DRILLING CCB#156965 • Equine Services • Internal • Nutritional medicine guidance • Surgery • Annual exams • Heartworm prevention • Vaccinations 59989 Hwy, John Day, OR 541-932-4428 Experienced Air Rotary Drilling • Licensed & Bonded Also: Complete Pump WWC# Installation & Service 1606 CALL FOR FREE ESTIMATES PAVING TIDEWATER CONTRACTORS INCORPORATED • Asphalt • Sand & Gravel • Concrete • Road Building • Excavation Blinds • Carpets • Floors • Windows • Ducts Upholstery • Power Sweeping • Snow Removal Fire & Flood Restoration #CCB 114195 NOTICE TO INTERESTED PERSONS NOTICE IS HEREBY GIVEN that Russell Young has filed a Complaint in Equity for Quiet Title in the Circuit Court for the State of Oregon, County of Grant for real property described as follows: INTERNET American Standard Sinks & Toilets, Delta Faucets Brandford White, Water Heaters 101 Legal Notices IN THE CIRCUIT COURT OF THE STATE OF OREGON FOR THE COUNTY OF GRANT SERVICE DIRECTORY PLUMBING 101 Legal Notices Between John Day and Prairie City 541-820-3329 SPORTS ANDY’S PLUMBING & SPORTS STORAGE R & S SELF-STOR A LL TYPES OF ARCHERY EQUIPMENT BOWS: Martin Jennings-Hoyt 245 N. Canyon Blvd., Canyon City 541-575-2144 731 W. Main, John Day Mon.-Fri. 8am-4:30pm Sports Store: Mon.-Thurs. 8am-4:30pm YOUR AD WELDING SUPPLIES • Industrial Gases • Industrial Machine Work • Full Automotive • Lincoln Wire and Rod • Replacement parts for welders, plasma cutters & torches • Special Orders Welcome QUALITY PARTS, QUALITY SERVICE, QUALITY PEOPLE JOHN MARCIEL MT. VERNON 721 W Main St, John Day, OR 97845 • (541) 575-1850 S204836-1 B6