Page 8—T he Portland Observer***January 2, 1991
Portland Observer
CLASSIFIEDS
INVITATION FOR BIDS TO
Sealed bids will be received at the Housing Authority of Portland (HAP) 8910 N.
W oolsey, Portland, OR 97204, until 2:00 p.m., Tuesday, January 22, 1991, for
labor and materials to re-roof 71 buildings. Shortly thereafter, bids will be opened
and publicly read. Bidders are welcomed.
the work consists of removing existing composition shingle roofs and installing
panel roofs at 71 buildings located in the Housing Project known as Columbia Villa,
generally located at 8910 N. Wooisey Avenue, Portland, Oregon.
Interested bidders may obtain one set of bid documents at the HAP Maintenance
Office located at 8910 N. Woolsey Avenue, upon receipt of $50 deposit, which is
refundable when documents are returned in good condition within 10 days after
bid opening. Additional sets may be acquired for $20 each, non-refundable.
A HAP representative will conduct a pre-bid tour of the project commencing at the
HAP Maintenance office located at 8910 N. Woolsey Avenue, Portland, OR
97203, at 10:00 a.m., P.S.T., on January 10,1991, and the attendance of bidders
is requested. An orientation will be given prior to moving to the project site.
Questions posed during the tour, when not addressed in the specifications, will be
answered by addendum and mailed to all bidders.
Attention is called to the provisions addressed in "Supplement to Instructions to
Bidders" regarding MBE participations to Division "H ," "Special Conditions," re­
garding Equal Employment Opportunity, EEO compliance reports, certification of
non-segregated facilities and a waiver from enforcing the payment of non-federal
prevailing wages when said wages, exclusive of any fringe benefits, exceeds the
applicable wage rate determined by the Secretary of HUD.
A bid security of 5% of the bid is required as prescribed in the “ Instructions to Bid­
ders" (Division B). No bidder may withdraw bid after the hour set for opening
thereof until after the lapse of sixty (60) days from the bid opening.
The Housing Authority of Portland may reject any bid not in compliance with the
prescribed bidding procedures and requirements, may reject any or all bids and
waive all informalities, if in the judgment of HAP, is is in the public interest to do so.
Questions regarding this project should be directed to David Walter at 283-1693.
HOUSING AUTHORITY OF PORTLAND
Loren Tarbell
D ire cto r o f M aintenance
SUB-BIDS REQUESTED
Mechanical and electrical packages
Pre-bid walk through required
Lake Grove Elementary School
Lake Oswego, Oregon
Bid Date: January 7,1991 @ 2:00 P.M.
EMERICK CONSTRUCTION CO. CCB #10723
P.O. Box 66100
Portland, Oregon 97266
(503)777-5531 FAX (503) 771-2933
We are an equal opportunity employer and request sub-bids from small disad­
vantaged business subcontractors and women and minority business
enterprises.
PUBLIC NOTICE
City of Portland Development Commission
Nursing
Occupational Health
And Safety Nurse
RE-ROOF 71 BUILDINGS AT
COLUMBIA VILLA, M9-0108
REQUEST FOR QUALIFICATIONS
Blue Cross and Blue Shield is now hiring for an Occupational Health &
Safety Nurse.
Qualified candidates will have:
1-2 years experience in emergency/immediate care nursing
Experience coordinating Safety Committees, Early Return-to-Work Pro­
grams, Hazard Communications Programs, and ergonomic workstation
assessments
Experience providing immediate care to injured/ill workers
Candidate must have current knowledge of government health/safety
regulations
Blue Cross and Blue Shield Of Oregon offers an excel employee benefits
package, flex-time work hours and competitive salary. Pre-employment
drug screening required. To assure your resume is processed immedi­
ately, place as #490 at the top of your resume or in your cover letter, or
you may apply in person btwn 9am-4pm M-F
Blue Cross
Blue Shield Of Oregon
Human Resources Dept., 5th Fir.
1OO S. W. Market
Portland, OR 97201
TDD #225-6780
Equal Opportunity Employer
INSURANCE
MEDICAL CLAIMS
ANALYSTS
Blue Cross and Blue Shield of Oregon is currently accepting applications
for Medical Claims Analysts. This position is responsible for accurate and
timely payment of blue Cross and Blue Shield of Oregon's medical
claims. Experience necessary to perform this task will include:
1 year recent clerical work experience in a doctor’s office or hospital set­
ting
Demonstrated knowledge of medical terminology and anatomy. This may
be obtained through a classroom setting or office experience
ICD-9/CPT » Coding
A minimum of 6-12 months experience using a CRT in a production
oriented environment
Fast, accurate use of a 10-key calculator
Previous claims processing or insurance billing experience highly desir­
able. Starting salary $1347/mo.
Blue Cross and Blue Shield of Oregon offers an excellent employee bene­
fits package, flex-time work hours, and competitive salary. Pre-employ­
ment drug screening required. To assure your resume is processed
immediately, place ad #457 at the top of your resume or you may apply
in person between 9 AM-4PM Mon-Fri.
Blue Cross
Blue Shield
of Oregon
Human Resources Dept. 5th Floor
100 S.W. Market
Portland, Or 97201
ADVERTISEMENT FOR BIDS
SALEM AREA TRANSIT FACILITIES REMODEL
Sealed bids for construction of Salem Area Transit Facilities Remodel, as described
in the Specifications and as shown on the Area mass Transit District (hereafter called
"Owner"), 3140 Del Webb Avenue NE, Salem, 97303-4165, until but not after 3:00
PM Local Time, Wednesday, January 23,1991, at which time all bids will be publicly
opened and read aloud in the Board Room at the same address. Bids received after
that time will not be considered.
Bids must be submitted on forms provided by the Architect, and addressed and
mailed or delivered to Sue Hollis, Contracting Officer, Salem Area Mass Transit
District, 3140 Del Webb Ave NE, Salem, OR 97303-4165. Bids must be in a sealed
envelope plainly marked "Salem Area Transit Facilities Remodel." Bids received
after the date and time specified above shall be considered late bids and shall be
returned to the Bidder unopened.
The Project includes minor demolition; gypsum board on wood stud partitions; lay-
in acoustical ceilings; casework; resilient flooring; carpeting, and contractor-de­
signed mechanical/electrical w o rk . Alternates, if accepted, will add remodeling of
additional space.
Bids shall be on a lump-sum basis; segregated bids will not be accepted. Work shall
be performed under one General Contractor which includes Mechanical and Elec­
trical Work. All contractors working on the project must be registered with the Oregon
Construction Contractors Board, as appropriate.
A Disadvantaged Business Enterprise (DBE) Goal of 10% has been established for
this project. Bidders must meet the goal or provide clear and convincing documen­
tation that a good faith effort was made to do so in order to be considered for award.
Bidding Documents and sample Contract may be examined at the Office of the
Architect, Settecase Smith Doss Architecture, 725 Commercial SE, Salem, OR
97301, and at the Builders Exchanges in Salem and Portland. On and after Decem­
ber 28,1990, Bidding Documents may be obtained at the Architect's Office upon
deposit of $25 per set. Deposit sum will be refunded, providing Documents are re­
turned in good condition within ten days after the bid date. Sub-bidders and Suppli­
ers may obtain parts of sets by paying the cost of reproduction.
Security in the amount of ten percent of the Base Bid must accompany each bid.
Bidders must certify on the form that they will comply with Oregon Revised Statute
(ORS) 279.350 relating to the prevailing wage law. The Bidder must also provide a
statement as to whether the Bidder is a resident Bidder as defined in ORS 279.029
(6) (B). Non-Oregon resident bidders from states with local preference laws may
have their bids adjusted for purposes of contract award.
A mandatory Pre-Bid Conference will be held at 10:30 AM, Local Time, Tuesday,
January 15,1991, at the Project Site, 195 High Street NE, Salem, OR. Prime con­
tractors wishing to submit a bid must attend. All others properly interested are invited
to attend.
No bidder may withdraw their Bid after the time set for the opening thereof, or before
award of the Contract, unless said award is delayed for a period exceeding thirty (30)
days.
Salem Area Transit reserves the right to reject any Bid not in compliance with all
prescribed public bidding procedures and requirements and may reject for good
cause any or all bids upon a finding of the agency that it is in the public interest to do
so.
SALEM AREA TRANSIT
SUE HOLLIS
CONTRACTING OFFICER
(503)588-2885
Holladay Park Medical Center
1225 N ortheast 2nd A ven u e
(503) 233-4567
itC A cv
Committed to Career Opportunity Jor A d Americans
24-Hour Job Line 239-3116
An Equal Opportunity Employer
A Legacy Member
SUB-BIDS REQUESTED
Science Court Site Improvements
University of Oregon
Eugene Oregon
Bid Date: January 9,1991 @ 4:00 P.M.
for
GENERAL CONTRACTOR FOR THE SHORELINE
BUILDING RENOVATION
Portland, Oregon
Statements of Qualifications due by 3:00 p.m. January 3 ,1991.
The Portland Development Commission (PDC) on behalf of the building owner,
Central City Concern (CCC), seeks Statements of Qualifications from general con­
tractors for the renovation of the Shoreline Building. The building is part of the City
of Portland single room Occupancy (SRO) Downtown Housing Preservation
Program commitment. The building is located on the northeast corner of the inter­
section of N.W. Second Avenue and W. Burnside Street and will contain approxi­
mately 62 units of SRO housing on two upper floors, commercial leased space
(presently occupied) and lobby space on the ground floor, and work in the base­
ment. Statements of Qualifications from general contractors will be evaluated and
the three (3) most qualified contractors, as determined by the Commission, will be
invited to submit Proposals to perform the work. These contractors must be pre­
qualified with the City of Portland prior to submitting their proposals. The construc­
tion work will be performed on a cost-plus-fixed-fee basis with a Guaranteed Maxi­
mum Price.
The Portland Development Commission is committed to acting affirmatively to en­
courage and facilitate the participation of Emerging Small Businesses (ESB), Mi­
nority Business Enterprises (MBE), and Women Business Enterprises (WBE) in
Comission projects and operations. The contractor selected for this project must
comply with ESB/MBE/WBE goals established by the Commission.
A copy of the Request for Qualifications and preliminary drawings will be available
by 3:00 p.m., Wednesday, December 19,1990, from Tony Poneck, PDC, (503)
823-3240, by depositing with the Portland Development Commission a check for
$15.00 per set, refundable upon return of the documents in re-useable condition.
Statements of Qualifications must be received by the Commission, attention of
Tony Poneck, at 1120 S.W. Fifth Ave., Suite 1100, Portland, Oregon 97204-1968
no later than 3:00 p.m., Thursday, January 3,1991.
PUBLIC NOTICE
City of Portland Development Commission
REQUEST FOR BIDS
for
ABATEMENT OF ASBESTOS AT THE SHORELINE
BUILDING
Portland, Oregon
Bids due by 2:00 p.m. January 3,1991.
The Portland Development Commission (PDC) on behalf of the building owner,
Central City Concern (CCC), seeks Bids from qualified asbestos abatement con­
tractors for the abatement of asbestos at the Shoreline Building. The building is
located on the northeast corner of the intersection of N.W. Second Avenue and
W. Burnside Street. The building is partially occupied and some abatement work
will be performed in occupied portions of the building. Bidders must be prequali­
fied with the City of Portland prior to submitting their bids. The abatement work will
be performed for a lump sum fixed amount.
The Portland Development Commissiion is committed to acting affirmatively to
encourage and facilitate the participation of emerging Small Businesses (ESB),
Minority Business Enterprises (MBE), and Women Business Enterprises (WBE)
in Comission projects and operations. The contractor selected for this project
must comply with ESB/MBE/WBE goals established by the Commission.
The Contract Documetns will be available after 8:00 a.m., Thursday, December
20, 1990, from Tony Poneck, PDC, (503) 823-3240, by depositing with the
Portland Development Commission a check for $15.00 per set,ref undable upon
return of the documents in reuseable condition. A mandatory pre-bid meeting will
be held at the offices of the Commission at 1:30 p.m., Thursday, December 20,
1990. A mandatgory pre-bid building walk-through will be held at the Shoreline
Building at 10:00 a.m., Friday, December 21,1990.
Bids must be received by the Commission, attention of Tony Poneck, at 1120
S.W. Fifth Ave., Suite 1100, Portland, Oregon 97203-1968 no later than 2:00
p.m., Thursday, January 3,1991, at which time bids will be publicly opened and
read aloud.
NO EXPERIENCE NECESSARY!
JOHN HYLAND CONST., INC.
P.O. Box 7867
Eugene, Oregon 97401
(503)345-8100 FAX (503) 741-0896
CCB # 46071
We are an equal opportunity employer and request sub-bids from disadvan­
taged, minority, women, and emerging small business enterprises.
ADVERTISEMENT FOR BID
Sealed bids for the Women’s Building Remodel for Conference Room project
will be received by the Oregon State Board of Higher Education until 2:00 PM,
local time, January 15,1991. Bids will be opened and publicly read aloud on
January 16,1991 at 2:00 PM, local time.
Additional information may be obtained by contacting the OSU Physical Plant,
Adams Hall, Corvallis, Oregon 97331-2001 or telephone 503-737-4921.
Baliche, Pacific Northwest Laboratories, a premier research and development
laboratory located in Richland. Washinqion, is currently recruiting for Quality
Assurance Professionals lor its expanding department
As a Quality Assurance Professional performing quality engineering assistance,
systems development, and QA program training, primary duties will include
evaluating, verifying and providing support Io a wide spectrum ol Baliche
activities.
JOB OPPORTUNITY
Call our 24-Hour JobLine at 280-4727
for a-lifting of current openings at
Emanuel Hospital & Health Center.
Qualified candidates should have a broad-base tuwwledrjo ol research and
development QA and QC principles A degree in Engineering or Physical
Science is strongly preferred
Located m south central Washington, the In Cities area otters abordable I tomes,
excellent schools, a low crim e rale, and plenty ol outdoor aclivilivs
Qualified candidates should sulxml a resume and salary history Io Baliche,
Pacific Northwest I a h o ra to n e s . H<>> ( „ iim e rV C e n te r. A lto M A A P ()
Box 1406, Richland, WA 99352. Women and minorities are encouraged Io
apply
EMANUEL HOSPITAL
& HEALTH CENTER
A ta to fit M B B M 4 C « « «
A Iw tm
A L»g»ry M»irp»r
Equal O pportune Employ»« MFH.
w
Pacific Northwest Laboratories
I A *
pP. *
*
]
I
I
...... come to the FREE
|
I
I
f ’KXL Northwest Career Fair")
!
I
I
I
Saturday, January 5, 1991 • 11-5
¡
I
i
Portland Memorial Coliseum
I
I
I meet potential employers • career counselors • educational g
I advisors • job recruiters • identify career trends of the 90’s • g
I attend free seminars on resumes, interviewing, and more! g
I
It's educational...Jt‘3 informative....and iVs FREE!
■
Q UALITY ASSURANCE
PROFESSIONALS
»*•<«.< » •» ♦ » J
» ■
w Advertising
^Employment
Bids/Sub-Bids
■
* .• _ Xi’it -
•• -J >
'’ ’a .
• •
•
. «,
.
’